- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 21 Feb 2018
Delays on construction projects
They are very complex, requiring the co-ordination of permissions, people, goods, plant and materials. Construction can begin despite many ‘unknown’ matters such as incomplete design information, uncertain site conditions, suppliers, and so on. As a consequence delays are common.
Delays might be caused by:
- The uniqueness of the project.
- Speed of decision making.
- Poor or unrealistic scheduling.
- Poor communication.
- Lack of information.
- Labour productivity.
- Availability of resources.
- Adversarial relationships.
- Third party dependencies.
- Lack of finance.
- Availability of the site.
- Site conditions.
Delays can be minimised by:
- Detailed site investigations.
- Careful monitoring and regular meetings.
- Effective site management.
- Collaborative working and effective coordination.
- Careful scheduling.
- Full commitment to the project by all parties.
Very broadly, there are two types of delay
- Delays in activities for which there is programme float available (i.e. they can be delayed without impacting on the completion date).
- Delays that will impact on the completion date.
- Delays resulting from neutral causes.
- Delays that are the fault of the client.
- Delays that are the fault of the contractor (culpable delay).
- Concurrent delays.
- Exceptionally adverse weather.
- Civil commotion or terrorism.
- Statutory undertaker’s work.
- Force majeure (such as a war or an epidemic).
- A specified peril such as flood.
- National strikes.
- Changes in statutory requirements.
- Delays in receiving permissions that the contractor has taken reasonable steps to avoid.
Where the progress of the works is materially affected by a matters for which the client is responsible, the contractor may be entitled to claim direct loss and expense incurred. Such matters might include:
- The client instructing variations in the works.
- Failure by the consultant team to provide information.
- Delay on the part of a nominated sub-contractor.
- Failure by the client to supply materials or goods.
- Delay in giving the contractor possession of the site.
These matters (described in some contracts as 'relevant matters') may also constitute 'relevant events' allowing the contractor to claim an extension of time, however a relevant matter need not necessarily result in a delay to the completion date, and so claims for loss and expense and claims for extensions of time do not necessarily always run together.
 Delays that are the fault of the contractor
For more information, see Culpable delay.
Concurrent delay refers to the complex situation where more than one event impacts on the completion date at the same time, but where not all of those events would entitle the contractor to claim an extension of time or loss and expense.
Some form of apportionment is likely here, however such situations are complex and each case will tend to have circumstances that are unique in some way. What is clear is that it is important for both parties to ensure they keep good records to demonstrate that the event did actually occur and that it did impact on the completion date.
If it is possible to carry out a critical path analysis that demonstrates the effect of events on the completion date, then this is beneficial, however, in the absence of such information it is likely that the courts will take a ‘common sense’ approach.
NEC contracts deal with these issues under the single heading ‘compensation events’. They do not treat compensation events as an allocation of blame, but rather an allocation of risk. Any risk that is not specifically identified as being attributed to the client is borne by the contractor.
When it becomes reasonably apparent that there is a delay, or that there is likely to be a delay that could merit an extension of time, the contractor must give written notice to the contract administrator identifying the relevant event that has caused the delay.
 Mitigation and acceleration
If there is nonetheless a delay, the client may wish to instruct acceleration of the works. An acceleration agreement can be used as a “wrap up” agreement expunging all outstanding claims for extensions of time and loss and expense.
Measures taken to accelerate the works might include
- Additional resources of manpower, plant and materials directly employed or subcontracted.
- Revised methodologies including off-site prefabrication, extra scaffolding, temporary weatherproofing and so on.
- Proposals for phased completion.
- Increasing working hours on and off site, including weekends, holidays, night working and shift working.
- Additional supervision.
- Changes to the design or specification (for example standardisation replacing bespoke solutions)
- Reduction in scope (for example transferring work to a separate post-contract agreement for occupational works).
 Related articles on Designing Buildings Wiki
- Compensation event.
- Concurrent delay.
- Conflict avoidance.
- Construction disputes.
- Constructive acceleration.
- Culpable delay.
- Dispute resolution.
- Disruption claims in construction.
- Extension of time.
- International research into the causes of delays on construction projects.
- Liquidated damages.
- Loss and expense.
- Programme for building design and construction.
- Relevant event.
- Relevant event v relevant matter.
- Relevant matter.
 External references
- Walter Lilly and Co Ltd v Mackay 2012.
- Royal Brompton Hospital National Health Trust v Hammond and Others.
- City Inn v Shepherd.
Featured articles and news
A PQP describes the activities, standards, tools and processes necessary to achieve quality in a project's delivery.
How Lidl has been actively working to reinforce their brand through sustainability.
Association of British Insurers describe full-scale cladding tests as 'utterly inadequate'.
This article examines the changing policy commitments and evolving definitions of the zero carbon home.
Researchers believe they may have created a 'game-changing' new form of concrete using graphene.
Grouting refers to the injection of materials into a soil or rock formation to change its physical characteristics.
Part of Designing Buildings Wiki, BREEAM Wiki will advance knowledge sharing for the BRE family of sustainability tools.
From the decorative to the utilitarian, and from the photographed to the forgotten.
New BRE book considers the progression from project-based knowledge creation to whole-life urban knowledge management.
This CIOB article explores the concept of value in building design and construction.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?