Thickening claims
At its simplest, thickening is a contribution to a claimant’s increased overheads resulting from a client-culpable delay. Thickening is a legal term used in claims when claimants are legally entitled to claim extra costs – over and above the direct costs they may be already claiming – as a result of a delay which is outside their control.
For example, where an extension of time is granted to a contractor, they may also be entitled to claim for time-related costs for the delay period, in other words, in addition to the claim for direct costs, they may also be able to claim for ‘thickened’ overheads resulting from client/employer culpable delay or disruption.
In thickening claims, the claimant must, for example, prove that their head-office overheads had ‘thickened’, i.e. had increased, as a result of the defendant’s breach.
A celebrated case of thickening from October 2016 was that between contractor Flour, which had been engaged to construct an offshore wind farm, and steel fabricator ZPMC. Cracking had occurred in the welding of the steel monopoles and the transition pieces of the turbines for which the court held ZPMC to be in breach of contract. Damages of £15m and €7m were awarded to Fluor as part of direct costs caused by the breach and included costs of additional project management staff, consultants’ costs for the remedial works and costs for extra plant and equipment, as well as for providing extra storage space.
However, in addition, Fluor also claimed for ‘thickening’ costs amounting to 4% of the award – comprising overheads to reflect the increased head-office costs that were necessitated as a result of dealing with the breach of contract. Fluor argued that the thickening costs were just as much a result of the breach as were the direct costs.
The landmark case introduced the concept that certain overhead costs can be linked to a breach of duty just as if they were ordinary losses, i.e. direct losses that include items such as new materials, extra labour and consultant costs necessitated by the breach.
[edit] Related articles on Designing Buildings Wiki
- Adjudication.
- Adversarial behaviour in the UK construction industry.
- Alternative dispute resolution.
- Arbitration.
- Causes of construction disputes.
- Civil procedure rules.
- Conflict avoidance.
- Contract sum.
- Contractual right.
- Construction contract.
- Dispute resolution.
- Dispute resolution boards.
- Disruption claims in construction.
- Expert witness.
- Extension of time.
- Final account.
- Housing Grants, Construction and Regeneration Act.
- How to prepare a claim for an extension of time.
- Litigation.
- Liquidated damages.
- Loss and expense.
- Mediation.
- Modifying clauses in standard forms of contract.
- Notice.
- Preliminaries.
- Scheme for Construction Contracts.
- Variation.
- What is a default?
Featured articles and news
For the World Autism Awareness Month of April.
70+ experts appointed to public sector fire safety framework
The Fire Safety (FS2) Framework from LHC Procurement.
Project and programme management codes of practice
CIOB publications for built environment professionals.
Sustainable development concepts decade by decade.
The regenerative structural engineer
A call for design that will repair the natural world.
Buildings that mimic the restorative aspects found in nature.
CIAT publishes Principal Designer Competency Framework
For those considering applying for registration as a PD.
BSRIA Building Reg's guidance: The second staircase
An overview focusing on aspects which most affect the building services industry.
Design codes and pattern books
Harmonious proportions and golden sections.
Introducing or next Guest Editor Arun Baybars
Practising architect and design panel review member.
Quick summary by size, shape, test, material, use or bonding.
Types of rapidly renewable content
From forestry to agricultural crops and their by-products.
Terraced houses and the public realm
The discernible difference between the public realm of detached housing and of terraced housing.