Thickening claims
At its simplest, thickening is a contribution to a claimant’s increased overheads resulting from a client-culpable delay. Thickening is a legal term used in claims when claimants are legally entitled to claim extra costs – over and above the direct costs they may be already claiming – as a result of a delay which is outside their control.
For example, where an extension of time is granted to a contractor, they may also be entitled to claim for time-related costs for the delay period, in other words, in addition to the claim for direct costs, they may also be able to claim for ‘thickened’ overheads resulting from client/employer culpable delay or disruption.
In thickening claims, the claimant must, for example, prove that their head-office overheads had ‘thickened’, i.e. had increased, as a result of the defendant’s breach.
A celebrated case of thickening from October 2016 was that between contractor Flour, which had been engaged to construct an offshore wind farm, and steel fabricator ZPMC. Cracking had occurred in the welding of the steel monopoles and the transition pieces of the turbines for which the court held ZPMC to be in breach of contract. Damages of £15m and €7m were awarded to Fluor as part of direct costs caused by the breach and included costs of additional project management staff, consultants’ costs for the remedial works and costs for extra plant and equipment, as well as for providing extra storage space.
However, in addition, Fluor also claimed for ‘thickening’ costs amounting to 4% of the award – comprising overheads to reflect the increased head-office costs that were necessitated as a result of dealing with the breach of contract. Fluor argued that the thickening costs were just as much a result of the breach as were the direct costs.
The landmark case introduced the concept that certain overhead costs can be linked to a breach of duty just as if they were ordinary losses, i.e. direct losses that include items such as new materials, extra labour and consultant costs necessitated by the breach.
[edit] Related articles on Designing Buildings Wiki
- Adjudication.
- Adversarial behaviour in the UK construction industry.
- Alternative dispute resolution.
- Arbitration.
- Causes of construction disputes.
- Civil procedure rules.
- Conflict avoidance.
- Contract sum.
- Contractual right.
- Construction contract.
- Dispute resolution.
- Dispute resolution boards.
- Disruption claims in construction.
- Expert witness.
- Extension of time.
- Final account.
- Housing Grants, Construction and Regeneration Act.
- How to prepare a claim for an extension of time.
- Litigation.
- Liquidated damages.
- Loss and expense.
- Mediation.
- Modifying clauses in standard forms of contract.
- Notice.
- Preliminaries.
- Scheme for Construction Contracts.
- Variation.
- What is a default?
Featured articles and news
Definition of Statutory in workplace and facilities management
Established by IWFM, BESA, CIBSE and BSRIA.
The general election and the construction industry
As PM, Rishi Sunak announces July 4 date for an election.
Tackling the lack of knowledge or confidence in heat pumps
The CICV Green Home Festival part of the Edinburgh Fringe.
Home improvements swapped for green energy upgrades
As applications down since and desire to reduce bills up.
Eco apprenticeships continue help grow green workforce
A year after being recognised at the King's coronation.
The Use of Natural Insulation Materials in Retrofit
New paper from STBA with support from SDF.
National Retrofit Hub in partnership with InstallerSHOW.
Permitted development rights for agricultural buildings
The changes coming into effect as of May 21, 2024.
Biodiversity and the built environment digital series
The nature of building, with CIOB and CWP.
A call for prevention and sensitive re-use.
Risks to the long-term effectiveness of the BNG scheme
National Audit Office publish review of Biodiversity Net Gain.
The CIAT principal designer register
Providing assurance and verification of the capability and competence of registered ATs.
Building Safety recommendations and Northern Ireland
The NI roadmap to improving safety in high rise residential.
Specifying rendered external wall insulation for fire safety
How to interrogate the evidence provided to the specifier.
The benefits of writing articles for your organisation
How to create a profile for your organisation and publish for free.
Scottish Government action to reach net-zero targets
Retrofit expert group highlight critical actions needed.
A forward thinking, inclusive global community of members.