- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 27 Aug 2020
Prime cost sum
A prime cost sum (PC or PC sum) is an allowance, usually calculated by the cost consultant, for the supply of work or materials to be provided by a contractor or supplier that will be nominated by the client (that is, a supplier that is selected by the client to carry out an element of the works and imposed on the main contractor after the main contractor has been appointed).
Payments are made based on the quotations/invoices of the supplied items by the contractor plus addition of reasonable/agreed percentages for overhead costs and profits. If the contractor's actual cost is higher than the bill of quantities allowance, then the contract sum will be increased to balance it up and if the cost to the contractor is lower, then the contract sum will be reduced by the balance.
- For long delivery items where design and manufacturing times could not wait for the appointment of a main contractor. For example, lifts, switchgear or refrigeration plant.
- Where specialist design input was required in the early stages of design development. For example, for a cladding system.
- Where the client directly orders a preferred piece of equipment on which design is to be based. For example, an MRI scanner, laboratory fume cupboards or bottling plant.
It should be noted that the courts have generally taken the view that risk in relation to the performance of a nominated sub-contractor lies with the client and not the contractor. This means that delay to the overall programme caused by a nominated sub-contractor can lead to a claim for extension of time under the main contract and entitlement to consequential losses.
NB: 'NRM1: Order of cost estimating and cost planning for capital building work' defines a prime cost sum as; '...a sum of money included in a unit rate to be expended on materials or goods from suppliers (e.g. supply only ceramic wall tiles at £36.00/m2, supply only door furniture at £90.00/door or supply only facing bricks at £390.00/1,000).
'It is a supply only rate for materials or goods where the precise quality of those materials and goods are unknown. PC Sums exclude all costs associated with fixing or installation, all ancillary and sundry materials and goods required for the fixing or installation of the materials or goods, subcontractor’s design fees, subcontractor’s preliminaries, subcontractor’s overheads and profit, main contractor’s design fees, main contractor’s preliminaries and main contractor’s overheads and profit.'
 Related articles on Designing Buildings Wiki
- Bill of quantities.
- Consequential loss.
- Contract conditions.
- Contract sum.
- Defined provisional sum.
- Final account.
- Nominated sub-contractor.
- Outturn cost.
- Payments to nominated sub-contractors.
- Prime cost price.
- Provisional sums.
- The difference between a prime cost sum and a provisional sum.
Featured articles and news
Survey reveals green skills gap.
America's economic collapse produced scores of PWA Moderne projects.
The benefits of glowing aggregates and cement.
Urgent need for open communication to address mental health issues.
Guidance offered on COVID-19 green recovery, building safety and more.
Providing strength and support above the joists.
Enforcer will test and investigate product safety.
Underfloor air conditioning comes to 24 St James's Square.
Consultation on public right to buy unused public property.
IHBC resource offers improved consistency.
New laws to ‘retain and explain’ historic statues.
The principles and art of the possible. Book review.