- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 12 Jan 2018
Relevant events v relevant matters
A relevant event is an event that causes a delay to the completion date, which is caused by the client, or a neutral event not caused by either party. The contract should set out what constitutes a relevant event. Relevant events entitle the contractor to claim an extension of time; that is for the completion date to be moved.
Relevant events might include:
- Exceptionally adverse weather.
- Civil commotion or terrorism.
- Failure to provide information.
- Delay on the part of a nominated sub-contractor.
- Statutory undertaker’s work.
- Delay in giving the contractor possession of the site.
- Force majeure (such as a war or an epidemic).
- Loss from a specified peril such as flood.
- The supply of materials and goods by the client.
- National strikes.
- Changes in statutory requirements.
- Delays in receiving permissions that the contractor has taken reasonable steps to avoid.
A relevant matter is a matter for which the client is responsible that materially effects the progress of the works. This enables the contractor to claim direct loss and / or expense that has been incurred.
Relevant matters might include:
- Failure to give the contractor possession of the site.
- Failure to give the contractor access to and from the site.
- Delays in receiving instructions.
- Opening up works or testing works that then prove to have been carried out in accordance with the contract.
- Discrepancies in the contract documents.
- Disruption caused by works being carried out by the client.
- Failure by the client to supply goods or materials.
- Instructions relating to variations and expenditure of provisional sums.
- Inaccurate forecasting of works described by approximate quantities.
- Issues relating to CDM.
If delays are not caused by the client and are not neutral events, but are caused by the contractor, and this results in a failure to achieve practical completion by the completion date set out in the contract, the contractor may be liable to pay liquidated damages to the client.
NEC contracts deal with these issues under the single heading ‘compensation events’. They do not treat compensation events as an allocation of blame, but rather an allocation of risk. Any risk that is not specifically identified as being attributed to the client is borne by the contractor.
 Related articles on Designing Buildings Wiki
Featured articles and news
This CIOB article explores the concept of value in building design and construction.
BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?
New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.
Arbitration is a private, contractual form of dispute resolution used in the construction industry.
The European Parliament has approved a revised Energy Performance of Buildings directive.
One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.
A stakeholder is anyone who has an interest in the process or outcome of a construction project.
BRE launches online self-assessment tool for ethical labour sourcing.
Tower refurbishment failed to meet safety standards on several counts, according to leaked report.