- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 21 Feb 2018
- Where a delay which impacts on the completion date is caused by the contractor (culpable delay), the contractor will be liable to pay liquidated and ascertained damages (LADs) to the client.
- Where a delay which impacts the completion date is not caused by the contractor, it may be a ‘relevant event’, for which the contractor may be entitled to an extension of time and to claim loss and expense incurred as a direct result of the delay.
Relevant events may include:
- Exceptionally adverse weather.
- Civil commotion or terrorism.
- Failure to provide information.
- Delay on the part of a nominated sub-contractor.
- Statutory undertaker’s work.
- Delay in giving the contractor possession of the site.
- Force majeure (events that are beyond the reasonable control of a party, such as a war or an epidemic).
- Loss from a specified peril such as flood.
- The supply of materials and goods by the client.
- National strikes.
- Changes in statutory requirements.
- Delays in receiving permissions that the contractor has taken reasonable steps to avoid.
When it becomes reasonably apparent that there is a delay, or that there is likely to be a delay that could merit an extension of time, the contractor gives written notice to the contract administrator identifying the relevant event that has caused the delay. If the contract administrator accepts that the delay was caused by a relevant event, then they may grant an extension of time and the completion date is adjusted.
Claims for extension of time can run alongside claims for loss and expense however, one need not necessarily lead to the other. The contractor is required to prevent or mitigate the delay and any resulting loss, even where the fault is not their own.
Mechanisms allowing extensions of time are not simply for the contractor's benefit. If there was no such mechanism and a delay occurred which was not the contractor’s fault, then the contractor would no longer be required to complete the works by the completion date and would only then have to complete the works in a 'reasonable' time. The client would lose any right to liquidated damages.
 Related articles on Designing Buildings Wiki
Featured articles and news
New BRE book considers the progression from project-based knowledge creation to whole-life urban knowledge management.
This CIOB article explores the concept of value in building design and construction.
BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?
New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.
Arbitration is a private, contractual form of dispute resolution used in the construction industry.
The European Parliament has approved a revised Energy Performance of Buildings directive.
One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.
A stakeholder is anyone who has an interest in the process or outcome of a construction project.
BRE launches online self-assessment tool for ethical labour sourcing.