Last edited 25 Oct 2014

Relevant matters in construction contracts

Relevant matters are referred to in some construction contracts, such as JCT contracts. A relevant matter is a matter for which the client is responsible that materially effects the progress of the works. This may enable the contractor to claim direct loss and / or expense that has been incurred. Relevant matters might include:

Failure to give the contractor possession of the site.
Failure to give the contractor access to and from the site.
Delays in receiving instructions.
Opening up works or testing works that then prove to have been carried out in accordance with the contract.
Discrepancies in the contract documents.
Disruption caused by works being carried out by the client.
Failure by the client to supply goods or materials.
Instructions relating to variations and expenditure of provisional sums.
Inaccurate forecasting of works described by approximate quantities.
Issues relating to CDM.

Relevant matters should not be confused with relevant events. A relevant event is an event that causes a delay to the completion date, which is caused by the client, or is a neutral event not caused by either party. Relevant events entitle the contractor to claim an extension of time; that is for the completion date to be moved. A relevant event does not necessarily entitle the contractor to claim loss and expense. Similarly, a relevant matter need not necessarily result in a delay to the completion date, and so may not always entitle the contractor to an extension of time.

NB NEC contracts deal with these issues under the single heading ‘compensation events’. They do not treat compensation events as an allocation of blame, but rather an allocation of risk. Any risk that is not specifically identified as being attributed to the client is borne by the contractor.

[edit] Find out more

Grouting refers to the injection of materials into a soil or rock formation to change its physical characteristics.

Part of Designing Buildings Wiki, BREEAM Wiki will advance knowledge sharing for the BRE family of sustainability tools.

From the decorative to the utilitarian, and from the photographed to the forgotten.

New BRE book considers the progression from project-based knowledge creation to whole-life urban knowledge management.

This CIOB article explores the concept of value in building design and construction.

BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.

Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.

A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?

New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.

Arbitration is a private, contractual form of dispute resolution used in the construction industry.

The European Parliament has approved a revised Energy Performance of Buildings directive.

One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.