Delay damages
NEC was first published in 1993 as the New Engineering Contract. It is a suite of construction contracts intended to promote partnering and collaboration between the contractor and client. The third edition NEC3 was published in 2005.
The term ‘delay damages’ refers to one of the 15 secondary options available as part of NEC3. ‘X7 – Delay damages (liquidated damages)’ can be selected in part 1 of the contract data, and the level of damages payable can be defined. If option X7 is selected, and the contractor does not achieve the completion date then delay damages will be due from the contractor. This is similar to liquidated damages (or liquidated and ascertained damages, sometimes referred to as LADs) in other forms of contract such as JCT contracts.
NEC guidance recommends that this option is included in most contracts. It is also recommended that the employer maintains a record of how delay damages are calculated in case they are challenged by the contractor. Delay damages are not a penalty, they must be based on a genuine calculation of damages. If they are not genuine, they may be considered a penalty by the courts and so will be unenforceable. Under these circumstances, the client would still be able to pursue a claim for breach of contract.
A contractor wishing to avoid a claim against them for delay damages, may make a delay claim, demonstrating that:
- A compensation event has occurred.
- The event caused a delay to the project’s completion.
Compensation events are similar to relevant events and relevant matters referred to in other forms of contract such as JCT contracts. Very broadly, compensation events tend to be those events that impact on the completion date, but are not the contractor’s fault. This might include events that are caused by the client, or neutral events such as exceptionally adverse weather.
A delay claim for a compensation event can only be made by the contractor if the event actually delays completion. This can require careful analysis where there are multiple possible causes of a delay to ascertain the impact of the compensation event itself.
Generally, there are two approaches that can be adopted for this sort of analysis:
- Prospective: An assessment at the time the event occurs.
- Retrospective: An assessment after the event has occurred.
Whilst there is no express guidance given in NEC3 as to which of the two methods to use, it is thought that the intention of NEC3 to solve problems as they occur, preferably before completion, makes the prospective approach more favourable. Although there remains a risk that this may result in the contractor being under or over-compensated.
However, courts may prefer the retrospective approach, as it can otherwise be difficult to establish a causal connection between the compensation event and the delay, and it also allows for the benefit of hindsight.
There is provision in clause X7.3 for a delay damages reduction in the event that the employer takes control of a part of the works prior to the completion.
[edit] Related articles on Designing Buildings Wiki
- Accepted programme.
- Articles of agreement.
- Compensation event.
- Contract conditions.
- Contractual chain.
- Contractual obligation.
- Cost reimbursable contract.
- Defects.
- Defined cost.
- Disallowed cost.
- Early warning notice.
- Extension of time.
- Key dates.
- Latham Report.
- Liquidated damages.
- NEC3.
- NEC contract change management systems.
- NEC early contractor involvement.
- Penalty.
- Period for reply.
- Procurement route.
- Time Risk Allowance TRA.
- Variations.
- Z clauses.
[edit] External references
- RICS Consultations - Delay damages
- RPC - Delay claims under NEC3
Featured articles and news
Winter gardens: A brief history and warm variations
Extending the season with glass in different forms and terms.
Restoring Great Yarmouth's Winter Gardens
Transforming one of the least sustainable constructions imaginable.
Construction Skills Mission Board launch sector drive
Newly formed government and industry collaboration set strategy for recruiting an additional 100,000 construction workers a year.
New Architects Code comes into effect in September 2025
ARB Architects Code of Conduct and Practice available with ongoing consultation regarding guidance.
Welsh Skills Body (Medr) launches ambitious plan
The new skills body brings together funding and regulation of tertiary education and research for the devolved nation.
Paul Gandy FCIOB announced as next CIOB President
Former Tilbury Douglas CEO takes helm.
UK Infrastructure: A 10 Year Strategy. In brief with reactions
With the National Infrastructure and Service Transformation Authority (NISTA).
Ebenezer Howard: inventor of the garden city. Book review.
The Grenfell Tower fire, eight years on
A time to pause and reflect as Dubai tower block fire reported just before anniversary.
Airtightness Topic Guide BSRIA TG 27/2025
Explaining the basics of airtightness, what it is, why it's important, when it's required and how it's carried out.
Construction contract awards hit lowest point of 2025
Plummeting for second consecutive month, intensifying concerns for housing and infrastructure goals.
Understanding Mental Health in the Built Environment 2025
Examining the state of mental health in construction, shedding light on levels of stress, anxiety and depression.
The benefits of engaging with insulation manufacturers
When considering ground floor constructions.
Lighting Industry endorses Blueprint for Electrification
The Lighting Industry Association fully supports the ECA Blueprint as a timely, urgent call to action.