- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 05 Feb 2014
Request for information RFI
A Request for Information (RFI) (occasionally referred to as a Technical Query) is a formal question asked by one party to a contract on a construction project to the other party. Typically this will be a request from the contractor to the client’s consultant team, but it may be between any of the parties, for example from a sub-contractor to a contractor.
RFI’s should set out:
- The details of project.
- The details of the party requesting the information.
- The date the query was raised.
- The nature of the information being requested.
- The date by which a response is required.
- Any supporting explanatory documents provided.
It may be necessary for the party receiving the RFI to seek further information from parties with whom they themselves have a contractual relationship in order provide a response. It is good practice to include this information from other parties with the response to the original RFI. This can create a chain of information, where for example a subcontractor requests information from the main contractor, who in turn requests information from the client’s consultant team and so on. It may then be appropriate for responses and any explanatory documents attached to them to be disseminated amongst the wider project team.
This creates a matrix of RFI’s that need to be carefully tracked, responded to and distributed appropriately. This process be managed using an information request schedule, or can be managed electronically.
It is important to record the dates that RFI’s are despatched, the dates by which responses are required and the dates that responses are received to provide evidence in the event that a dispute arises.
Contractually, the requirement to respond to an RFI is created by the obligation to provide further information as is necessary to enable the other party to complete the contract on time. Requests should however give sufficient notice for the respondent to be able to resource and prepare a reply by the date that the information is required. The parties are then entitled to rely on the information provided as correct.
Failure to provide necessary information may qualify as a relevant event for which the contractor may be entitled to an extension of time and to claim loss and expense incurred as a result of any delay. Similarly, a response which constitutes a variation in the nature of the works may qualify as a relevant event for which the contractor may be entitled to an extension of time and to claim loss and expense.
A contractor’s master programme (generally prepared immediately after the execution of the contract and issued to the contract administrator for comment) may constitute a request for information. Similarly, a client information release schedule may constitute a commitment to provide information by certain dates, whether or not these dates are necessary to achieve the completion date.
 Related articles on Designing Buildings Wiki
Featured articles and news
Grouting refers to the injection of materials into a soil or rock formation to change its physical characteristics.
Part of Designing Buildings Wiki, BREEAM Wiki will advance knowledge sharing for the BRE family of sustainability tools.
From the decorative to the utilitarian, and from the photographed to the forgotten.
New BRE book considers the progression from project-based knowledge creation to whole-life urban knowledge management.
This CIOB article explores the concept of value in building design and construction.
BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?
New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.
Arbitration is a private, contractual form of dispute resolution used in the construction industry.
The European Parliament has approved a revised Energy Performance of Buildings directive.
One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.