- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 16 Jan 2018
Common refusals of extensions of time
When it becomes reasonably apparent that there is, or that there is likely to be, a delay that could merit an extension of time, the contractor should give written notice to the contract administrator identifying the relevant event that has caused the delay. If the contract administrator accepts that the delay was caused by a relevant event, then they may grant an extension of time and the completion date is adjusted.
Common reasons for the refusal of an application for extensions of time include:
- Where the contractor has underperformed, for example as a result of insufficient workforce or failure to obtain plant, goods or service.
- When there has been poor, but not exceptionally adverse weather.
- When the evidence or other information presented to demonstrate that the contractor has suffered irrecoverable delays is insufficient.
- If an extension of time has already been given for that event.
- Where more than one event occurs at the same time. See concurrent delay for more information.
- The event cited does not constitute a relevant event.
- An event does not constitute force majeure.
- An event does not constitute a specified peril.
- The contractor has not taken steps to mitigate the delay
 Related articles on Designing Buildings Wiki
- Acceleration of construction works.
- Change order.
- Compensation event.
- Contract administrator.
- Contract claims.
- Culpable delay.
- Delay damages.
- Extension of time.
- Extension of time - approval letter example.
- How to prepare a claim for an extension of time.
- Practical completion.
- Project programme.
- Time Risk Allowance TRA.
Featured articles and news
New BRE book considers the progression from project-based knowledge creation to whole-life urban knowledge management.
This CIOB article explores the concept of value in building design and construction.
BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?
New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.
Arbitration is a private, contractual form of dispute resolution used in the construction industry.
The European Parliament has approved a revised Energy Performance of Buildings directive.
One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.
A stakeholder is anyone who has an interest in the process or outcome of a construction project.
BRE launches online self-assessment tool for ethical labour sourcing.