Global claim
Claims commonly arise between the parties to construction contracts. This can be as a result of problems including; delays, changes, unforeseen circumstances, insufficient information, and conflicts. Claims might be made for loss and expense, extension of time, liquidated damages and so on. The contract should set out what can constitute a claim and how it should be dealt with.
However, as construction is a complex process, there is not always a straight-forward relationship between one particular breach and one specific effect. As a result, in some circumstances, contractors may make a ‘global claim’ by rolling together a number of different breaches and making a case for a cumulative effect resulting in a single total cost without attributing actual costs to specific events.
Global claims have not always found favour with the courts, as they can ignore other reasons for the delay or disruption, and they place the burden of proof on the employer to carry out a detailed assessment of the claim and how it has been constituted.
They can also be counter-challenged by the client, citing contractor’s deficiencies such as; labour shortages, poor management, plant breakdowns and subcontractor non-performance.
Keating on Construction Contracts describes a global claim as ‘...one that provides an inadequate explanation of the causal nexus between the breaches of contract or relevant events/matters relied upon and the alleged loss and damage or delay that relief is claimed for.’
In the case of Walter Lilly v Mackay & DMW (2012), Mr Justice Akenhead said, ‘What is commonly referred to as a global claim is a contractor’s claim which identifies numerous potential or actual causes of delay and/or disruption, a total cost on the job, a net payment from the employer and a claim for the balance between costs and payment which is attributed without more and by inference to the causes of delay and disruption relied upon'
However he went on to quote Mr Justice Donaldson in Crosby v Portland UDC, who stated ‘… it may well be difficult or even impossible to make an accurate apportionment of the total extra cost between the several causative events... I can see no reason why (the arbitrator) should not recognise the realities of the situation and make individual awards in respect of those parts of individual items of the claim which can he dealt with in isolation and a supplementary award in respect of the remainder of the claims as a whole.’
A global claim may be the only route available to the contractor, and the courts may accept this, however, where possible it is considered that it is better to be specific rather than generic. This is a more painstaking exercise requiring that the claimant lists each alleged default, linking it to the delay or disruption and its knock-on effect, all backed by clear records. This is more precise way of establishing quantum and is likely to lead to a more factually-based judgement.
NB, the Society of Construction Law Delay and Disruption Protocol, 2nd edition, defines a global claim as: 'one in which the Contractor seeks compensation for a group of
Employer Risk Events but does not or cannot demonstrate a direct link between the loss
incurred and the individual Employer Risk Events'.
[edit] Related articles on Designing Buildings Wiki
- Alternative dispute resolution.
- Adjudication.
- Arbitration.
- Causes of construction disputes.
- Construction contract.
- Contract claims.
- Dispute resolution boards.
- Extension of time.
- Housing Grants, Construction and Regeneration Act.
- Litigation.
- Liquidated damages.
- Loss and expense.
- Mediation.
- Scheme for Construction Contracts.
Featured articles and news
Review and comment on the revised draft before July 11.
We are indeed now 10 years old, so go on and be bold !
Write about something you know, help us build and grow !
IHBC's 25th anniversary 2022 Aberdeen School.
A blended event and triumphant return.
New Construction Leadership Council Co-Chair selected.
Mark Reynolds succeeds Andy Mitchell as Co-Chair of CLC
Designing Buildings is 10 years old.
Types of work to existing buildings.
From alteration to deconstruction on DB.
Publication available
BSRIA Conference 2022, June 23.
Refurbishment for Net Zero.
In the sunshine things get hotter.
Understanding temperature in buildings on DB.
Giving power to the consumer on the road to net-zero.
A call for home energy management to be modernised.
How many different types can you think of ?
50th anniversary of the first Pride parade UK.
Looking back and fourth to what still needs to be done.
Cleaning up air quality and the Environment Act 2021.
Targets, impacts and action from ECA member.
Balkrishna Doshi wins Royal Gold Medal 2022.
Pioneering Indian environmental design Architect.
The greenest building is the one already built.
History of Temple Meads rewritten.
UK crying out for female tradespeople says CIOB research.
Currently standing at just 1%.
Find out more with BSRIA.
A cricket pitch is 1 chain long whilst 80 chains is a mile.
What is your pledge ?
Cabman shelters.
Changes come into force for F,L,O and S.
CIAT member reasons on why it matters.
Are there still ‘lessons to learn’ from Grenfell ?
Nine in ten civil engineers think so.
IHBC Annual School, 15-18 June.
The Jubilee® worm drive hose clip or Jubilee clip.
A trusted clip with a long history, worth celebrating.
The new wave of green architectural features in context.
CIAT report on new route to CSCS cards
For built environment professionals.