- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 06 Feb 2018
Frustration in construction contracts
Frustration occurs when circumstances that are not the fault of either party to a contract mean it is impossible to continue with the contract. As a result, the contract comes to an end without either party being considered to be in breach. However, the parties must be certain that a frustration event has occurred so as not to be in breach of contract.
Frustration is a common legal principle, but it is applied as narrowly as possible by the courts - it does not cover contracts that were always going to be impossible to perform. For example, it would not apply in the case of a contract to construct a tall building that could not be fulfilled because the ground conditions were completely unsuitable.
Some events that may lead to a frustrated contract include:
- The government imposing unforeseen restrictions on building.
- Laws being passed that make it illegal to undertake what was promised under the contract
- The building where works were to be carried out being destroyed.
- An event that was crucial for the contractual obligations being cancelled.
Sometimes a party may try to claim a contract is frustrated when they are obligated to make payments in a different currencies which then fluctuates. However, this does not necessarily amount to frustration.
Events that do not alter the obligations but instead delay performance, such as a workforce strike, don’t necessarily amount to frustration. However, it might do should the events have a particularly serious effect on the obligations or if the delay is particularly long.
Force majeure provisions might provide for circumstances that could otherwise be considered frustration events, and so result in termination of the contract. However, generally, force majeure (for example, exceptionally adverse weather conditions) is considered a relevant event which construction contracts allow for by an extension of time rather than termination.
 Find out more
 Related articles on Designing Buildings Wiki
Featured articles and news
When is there a right to light, and what happens if it is obstructed?
What would the nationalisation of economic infrastructure mean for GB?
A new guide to improving value by reducing design error.
We've reached 80,000 page views a day and 10,000 registered users. Why not join them?
A masterplan is a framework within which a location is encouraged to develop or change. Read our introductory article.
New consultation announced on a specialist Housing Court to settle landlord-tenant disputes.
ICE responds to a transport consultation advising the government to make decisions enabling more inclusive cities.
BRE and Loughborough University complete first phase refurbishment of demonstration home.
How the risk of collapse of fibrous plaster ceilings is being addressed in theatres.
If you’re a great writer and have practical experience of the construction industry, it could be you.
Frustrated by long documents or technical jargon? Put off by sign-up forms or costs? Take this 5 min survey to help improve construction knowledge.