- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 26 Oct 2020
Frustration in construction contracts
Frustration occurs when circumstances that are not the fault of either party to a contract mean it is impossible to continue with the contract. As a result, the contract comes to an end without either party being considered to be in breach. However, the parties must be certain that a frustration event has occurred so as not to be in breach of contract.
Frustration is a common legal principle, but it is applied as narrowly as possible by the courts - it does not cover contracts that were always going to be impossible to perform. For example, it would not apply in the case of a contract to construct a tall building that could not be fulfilled because the ground conditions were completely unsuitable.
- The government imposing unforeseen restrictions on building.
- Laws being passed that make it illegal to undertake what was promised under the contract
- The building where works were to be carried out being destroyed.
- An event that was crucial for the contractual obligations being cancelled.
Sometimes a party may try to claim a contract is frustrated when they are obligated to make payments in a different currencies which then fluctuates. However, this does not necessarily amount to frustration.
Events that do not alter the obligations but instead delay performance, such as a workforce strike, don’t necessarily amount to frustration. However, it might do should the events have a particularly serious effect on the obligations or if the delay is particularly long.
Force majeure provisions might provide for circumstances that could otherwise be considered frustration events, and so result in termination of the contract. However, generally, force majeure (for example, exceptionally adverse weather conditions) is considered a relevant event which construction contracts allow for by an extension of time rather than termination.
 Related articles on Designing Buildings Wiki
Featured articles and news
Standard will help employers foster wellbeing and manage psychosocial risks.
Global fire standards for safety of people and property.
An introduction to the 5 core principles of lean.
Can the profession use its skills to save the world from climate change?
How faulty science resulted in sanitation reform.
Improving facilities, accessibility and overall appearance.
Free download of TG 12/2021 available.
TESP works with The Youth Group to form skill sharing network.
Big tech collaborates on platform for the built environment.
Letter signed by 21 organisations sent to MHCLG.
A look at the Government's strategic approach.
Steps to help reduce the spread of infection inside buildings.
This social media-centred hobby can be both dangerous and illegal.
Millwork wall treatment with a long and illustrious history.
Click the button to subscribe.