- Project plans
- Project activities
- Legislation and standards
- Industry context
- Specialist wikis
Last edited 28 Oct 2020
As construction nears completion there can be considerable pressure to allow the client or tenants to take possession of part of a building or site, even if the works are ongoing or there are defects that have not been rectified.
Early use allows the client to use part of the site before the project is completed, i.e. practical completion is not deemed to have occurred. With early use, the risk remains with the contractor. This differs from partial possession, whereby the risk passes to the client, and any part to which it is given use is deemed to have achieved practical completion.
In addition to the certification of practical completion not being triggered by early use, neither is the commencement of the rectification period, release of retention, or liquidated and ascertained damages (LADs). However, if any delay or disruption is caused by the client to the works as a result of their early use, it may bring about claims by the contractor for extensions of time, as well as loss and expense.
It can be difficult to distinguish between partial possession and early use, and the application of the terms will often depend on the particular circumstances, the correspondence between the parties, and the provisions of the contract. Often, parties will adapt the standard forms of contract to make it easier to distinguish, such as by including an agreed access regime clarifying when and how the client can occupy works without triggering partial possession. It can also be amended so that the contractor waives their rights to make a claim for extension of time.
The courts tend to focus on establishing which is the relevant part of the site and which party has exclusive possession of it. If the client has exclusive possession then partial possession provisions will apply. If the contractor has exclusive possession then the early use provisions will apply.
 Related articles on Designing Buildings Wiki
Featured articles and news
Take just two minutes to provide your feedback.
An update of standards and regulations are under consideration.
Exploring the key to the adoption of this abundant energy source.
His clients have ranged from Liberace to St Nick to world-class athletes.
These tactical structures can be permanent or temporary.
Organisation recognises milestones of the project's next phase.
Welding and metalworking businesses must manage respiratory risks.
New report explores how regulations are being put into action.
The golden thread and BS 8644-1.
Bitumen binder may delay road surface deterioration.
A varied portfolio of internationally recognised buildings.
Threatened by housing and expanding universities.
Getting "boots on the ground" to make things happen.
Building systems may begin to learn.