- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 18 Jul 2019
As construction nears completion there can be considerable pressure to allow the client or tenants to take possession of part of a building or site, even if the works are ongoing or there are defects that have not been rectified.
Early use allows the client to use part of the site before the project is completed, i.e. practical completion is not deemed to have occurred. With early use, the risk remains with the contractor. This differs from partial possession, whereby the risk passes to the client, and any part to which it is given use is deemed to have achieved practical completion.
In addition to the certification of practical completion not being triggered by early use, neither is the commencement of the rectification period, release of retention, or liquidated and ascertained damages (LADs). However, if any delay or disruption is caused by the client to the works as a result of their early use, it may bring about claims by the contractor for extensions of time, as well as loss and expense.
It can be difficult to distinguish between partial possession and early use, and the application of the terms will often depend on the particular circumstances, the correspondence between the parties, and the provisions of the contract. Often, parties will adapt the standard forms of contract to make it easier to distinguish, such as by including an agreed access regime clarifying when and how the client can occupy works without triggering partial possession. It can also be amended so that the contractor waives their rights to make a claim for extension of time.
The courts tend to focus on establishing which is the relevant part of the site and which party has exclusive possession of it. If the client has exclusive possession then partial possession provisions will apply. If the contractor has exclusive possession then the early use provisions will apply.
 Related articles on Designing Buildings Wiki
Featured articles and news
Brick slip soffit systems and intricate brick features.
Breaking down possible steps of pre-contract management.
ICE event includes comments from Welsh Government Minister Julie James.
How to write them and what they should include.
Designing Buildings Wiki becomes the world's first website to adopt the new knowledge standard.
Assessing the most beneficial design elements.
Exploring different types of vinyl flooring.
New Government task force will build beauty into reformed planning process.
Five outstanding aspects of the profession.
The seismic strengthening of historic churches.
Results show guarded optimism and payment concerns.
Noteworthy navigable aqueducts.