- Project plans
- Project activities
- Legislation and standards
- Industry context
- Specialist wikis
Last edited 07 Nov 2020
Octoesse LLP v Trak Special Projects Ltd
Octoesse LLP (the claimant) entered into an amended JCT Intermediate Building Contract with Trak Special Projects Ltd. (the defendant) for the construction of residential units. Practical completion was significantly later than the original completion date, and the defendant submitted a claim for an 18-week extension of time. They were awarded 9.5 weeks by the contract administrator. No further certificate of non completion was issued.
When the defendant issued a final certificate for payment, the claimant issued a pay less notice which deducted liquidated damages. An adjudication was begun by the defendant on the grounds that the pay less notice was invalid.
'If the Contractor fails to complete the Works or a Section by the relevant Completion Date, the Architect/Contract administrator shall issue a certificate to that effect. If an extension of time is made after the issue of such certificate, the extension shall cancel that certificate and the Architect/Contract Administrator shall where necessary issue a further certificate.'
The defendant argued that it was an express condition of the claimant’s entitlement to deduct liquidated damages that the contract administrator issued a certificate of non completion. Further, the effect of clause 2.22 was that when the extension of time had been given, it had cancelled the certificate of non completion.
If, on the other hand, the claimant had given notice of their intention to deduct damages, but an extension of time had then been made and a further certificate of non completion issued, then they would not need to give notice of the intention to deduct again.
 Find out more
 Related articles on Designing Buildings Wiki
Featured articles and news
BG 50 & VDI 2035 – your questions answered.
Will the way we heat homes change when winter comes ?
Can XR technology be leveraged in design & construction?
Or are you capping.
Digital gaming competition for UK students aged 16 to 18.
Heritage protection in England vs Australia.
Three-quarters of fire doors fail inspections
The role of geoparks, biospheres and world heritage sites.
Just one month to go ! Find out more here.
A new gallery for the University of Huddersfield.
What will it take to stop it ?
To celebrate world bee day 2022 !
Not forgetting part F and the new part overheating part O.
As energy prices jump up in cost.
With people in the UK from Ukraine.
Industry leader Steve Murray takes on role.
An abundant and versatile building material.
600,000 heat pump installations targeted per year by 2028.
Helping prevent those unwanted outcomes.
How has transport changed due to Covid-19 ?
Will you need it ? after June 15 and the new Part O ?