- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 29 Nov 2020
Contractual prevention principle
In relation to contracts, the prevention principle dictates that parties to a contract cannot enforce an obligation on the other party if they themselves have prevented that party from performing the obligation.
For example, if a client prevents a contractor from completing works by the date set out in the contract, they cannot claim liquidated and ascertained damages against the contractor. They must either allow an extension of time, or the completion date will be 'at large', that is, the contractor will only be obliged to complete the works within a reasonable time.
 Related articles on Designing Buildings Wiki
Featured articles and news
Report includes sales vs production of compressors by type.
Government announces latest plans for growth.
Will the new requirements - once passed - go far enough?
These post-WWII modular buildings were unpopular, yet ubiquitous.
What's the verdict from the court of public opinion?
Shift to home-based work influences closed plan preferences.
An overview of the current state of the market.
Organisation offers best practices for construction and modification.
Heritage on the edge?
Prioritising tax considerations.
The four D creative process: discover, define, develop and deliver.
National Cyber Security Centre initiative is announced.
Reviewing trends and projections.
Legislation will establish initiatives to move towards net zero.