- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 04 Nov 2016
In its broadest sense, the term 'due diligence' simply refers to taking reasonable steps or exercising reasonable care in relation to a particular course of action.
In relation to the construction industry, it can have a number of more specific meanings.
 Business assessment
Due diligence can refer to the steps taken to thoroughly investigate a business or person prior to signing a contract with them.
 Technical investigations
For more information, see Technical due diligence.
 Contractor's obligation
Due diligence may be referred to in a construction contract, placing an obligation on the contractor to complete the works with care and the ‘requisite effort’. A similar term may refer to ‘ordinary care’, that is, the care that a reasonable person would take to avoid harm to other persons or property.
In the case of Sabic UK Petrochemicals Limited v Punj Lloyd Limited, the Technology and Construction Court (TCC) had to examine whether a contractor was in breach of this obligation with regard to the delivery of a petrochemical plant.
The contractor maintained that due diligence required them to maintain an appropriate rate of progress, with regard to the contract requirements, and the completion date that was realistic at the time their rate of progress was being assessed. They claimed that due diligence did not extend to them being obliged to achieve the impossible, and they were not required to accelerate the works to claw back delays.
The TCC disagreed with the contractor and ruled that just because compliance with one or more of the absolute contractual obligations has become unachievable does not mean or imply that these obligations are objectively incapable of achievement. It would be necessary for the contractor to prove the impossibility of complying with the absolute contractual obligation.
They also held that the contractual terms did not suggest that the due diligence obligation should be ‘emptied of content’ as a result of the completion date becoming unachievable. Circumstances may arise, the court found, where the exercising of due diligence may require taking measures not originally contemplated, such as acceleration measures in the case of a delay, if that is what is required.
 Related articles on Designing Buildings Wiki
Featured articles and news
This CIOB article explores the concept of value in building design and construction.
BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?
New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.
Arbitration is a private, contractual form of dispute resolution used in the construction industry.
The European Parliament has approved a revised Energy Performance of Buildings directive.
One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.
A stakeholder is anyone who has an interest in the process or outcome of a construction project.
BRE launches online self-assessment tool for ethical labour sourcing.
Tower refurbishment failed to meet safety standards on several counts, according to leaked report.