Ampurius Nu Homes Holdings Ltd v Telford Homes (Creekside) Ltd (2012) EWHC 1820
High Court (Chancery Division) (England and Wales) 2012
The claimant and the defendant (a construction company) entered into a contract for the construction and grant of long leases on a development scheme for which the defendant acquired the freehold. The defendant was required under the contract to proceed with 'due diligence' and to 'use reasonable endeavours' to complete the works by the target date. However, the defendant ran into financial difficulties ceased work.
Judgment was given in favour of the claimant.
In so doing, The court held that the defendant was in breach of the term of the contract requiring due diligence by failing to carry out the works assiduously or expeditiously. It was also held that although the breach may not have been repudiatory at the outset, it could become so over time if it deprived the innocent party of the benefit of a significant part of the contract. Negotiation over the course of the breach did not mean the claimant had affirmed the contract.
Court of Appeal (Civil Division) (England and Wales) 2013
In 2013 this decision was overturned by the Court of Appeal. It was not disputed that Telford had been in breach of contract, but the court held that an 18 month delay on a 999-year lease was not sufficient to constitute a repudiatory breach (a breach that it indicates one party no longer intends to accept its obligations under the contract, allowing the innocent party to terminate the contract and to sue for damages) and so did not entitle Ampurius to terminate the contract.
 External references
Featured articles and news
This article explains the Buildings Regulations completion certificate, what it is, and when its needed.
Graphene has many potential applications, but when will it start being used in civil engineering?
Increasing productivity – now more than ever as we lead up to Brexit – should be the sector’s number one priority in 2018.
Carillion's collapse causes Construction Leadership Council to delay the construction sector deal report.
Urban Heritage, Development and Sustainability: international frameworks, national and local guidance.
What will the General Data Protection Regulations (GDPR) mean for you when they come into force in May?
Business Secretary chairs a new taskforce to monitor and advise on mitigating the impacts of Carillion’s liquidation.
Sir John Armitt is appointed the new chair of the National Infrastructure Commission.
High quality and high density homes - is it what we need or is it storing up trouble?
Government announces its intention to strengthen planning rules to protect music venues and neighbours.
National Audit Office reports that there is little evidence that PFI offers better value than other forms of contracting.
What is liquidation and how does it apply to contractors in the construction industry?