Early warning notice
See also: NEC early warning notices - a tool of mutual benefit.
The NEC Engineering and Construction Contract 3rd Edition (NEC3) was published in June 2005. It has been adopted as the contract of choice by the government who no longer update the GC Works contracts, and has been endorsed by the ICE whose own suite of contracts will no longer be updated.
The contract makes provision for early warning procedures. Both parties must give early warning of anything that may delay the works, or increase costs as soon as they become aware of them. They should then hold an early warning meeting to discuss how to avoid or mitigate impacts on the project.
If the contractor fails to give early warning of a possible delay to the works, or increase in costs, they will only be compensated for effects that would have remained anyway even if they had given early warning.
If the contractor fails to give early warning of an event that may give rise to a possible delay to the works, or increase in costs, within 8 weeks of becoming aware of the event, they will not be entitled to a change in price, completion date or key date, unless the project manager should have notified the event to the contractor but did not.
They grey area here is whether and when the contractor should have been aware of the event. Judgement is likely to come down to whether and when it would have been reasonable to expect an experienced contractor to be aware of the event.
NB the term 'early warning' can also be used to refer to the identification of a wider hazard such as a climate event. Glossary: Resilience, published by the Department for International Development in 2016, defines an Early Warning System as: ‘The set of capacities needed to generate and disseminate timely and meaningful warning information to enable individuals, communities and organisations threatened by a hazard to prepare and to act appropriately and in sufficient time to reduce the possibility of harm or loss.’
[edit] Related articles on Designing Buildings
- Accepted programme.
- Adversarial behaviour in the UK construction industry.
- Compensation event.
- Delays on construction projects.
- Disallowed cost.
- Duty to warn.
- Extension of time.
- Liquidated damages.
- Loss and expense.
- NEC early warning notices - a tool of mutual benefit.
- NEC3.
- Relevant event.
- Relevant matter.
Featured articles and news
Grenfell Tower Inquiry announcement
Phase 2 hearings come to a close and the final report due in September.
Progress from Parts L, F and O: A whitepaper, one year on.
A replicated study to understand the opinion of practitioners.
A distinct type of countryside that should be celebrated.
Should Part O be extended to existing buildings?
EAC brands heatwave adaptation a missed opportunity.
Definition of Statutory in workplace and facilities management
Established by IWFM, BESA, CIBSE and BSRIA.
Tackling the transition from traditional heating systems
59% lack the necessary information and confidence to switch.
The general election and the construction industry
As PM, Rishi Sunak announces July 4 date for an election.
Home improvements swapped for green energy upgrades
As applications down since and desire to reduce bills up.
Eco apprenticeships continue help grow green workforce
A year after being recognised at the King's coronation.
The Use of Natural Insulation Materials in Retrofit
New paper from STBA with support from SDF.
National Retrofit Hub in partnership with InstallerSHOW.
Permitted development rights for agricultural buildings
The changes coming into effect as of May 21, 2024.
Biodiversity and the built environment digital series
The nature of building, with CIOB and CWP.
A call for prevention and sensitive re-use.
Risks to the long-term effectiveness of the BNG scheme
National Audit Office publish review of Biodiversity Net Gain.
The CIAT principal designer register
Providing assurance and verification of the capability and competence of registered ATs.
Scottish Government action to reach net-zero targets
Retrofit expert group highlight critical actions needed.
Comments
[edit] To make a comment about this article, or to suggest changes, click 'Add a comment' above. Separate your comments from any existing comments by inserting a horizontal line.