- Project plans
- Project activities
- Legislation and standards
- Industry context
Last edited 02 Mar 2018
Adverse weather during construction
Where there is a delay to a construction project which impacts on the completion date, and that delay was not caused by the contractor, it may constitute a relevant event (or compensation event), for which the contractor may be entitled to an extension of time and in some cases loss and expense.
Some contracts list exceptionally adverse weather conditions as one such event. Even if it is not specifically mentioned however, it may still qualify as a neutral matter that adversely affects the completion date.
The question then is what constitutes exceptionally adverse weather, rather than general adverse weather that the contractor should have allowed for in their price. Unhelpfully, contracts do not always define the term (for example JCT contracts), leaving it to the discretion of the contract administrator, and so opening up a potential source of dispute.
Where it is defined, it tends to be weather that is exceptionally adverse for that time and location. NEC contacts state that this is where the weather over a calendar month has occurred on average less frequently than once in ten years. This means that a short period of poor weather is unlikely to qualify, and that if poor weather crosses two calendar months it may not qualify even if it has lasted for a considerable time. The location and types of weather to be measured should be set out in the Contract Data.
Generally, information should be collected from a weather station close to the site (from which historical records are available), or on site and compared with met office data. This may include information such as; the amount and duration of rainfall, air temperature and duration, volume and duration of lying snow, wind speed and so on, depending on the nature of the works.
It is likely that this approach would also be accepted on projects using forms of contract in which there is no definition.
Even where exceptionally adverse weather is defined in the contract and can be shown to have occurred, it must still be proven that this was the cause of a delay and on some forms of contract, that the contractor has used their best endeavours to mitigate any delay. Again, this is a potential source of dispute, and so good record keeping is necessary, and the correct procedures of notification must be followed.
 Related articles on Designing Buildings Wiki
Featured articles and news
Part of Designing Buildings Wiki, BREEAM Wiki will advance knowledge sharing for the BRE family of sustainability tools.
From the decorative to the utilitarian, and from the photographed to the forgotten.
New BRE book considers the progression from project-based knowledge creation to whole-life urban knowledge management.
This CIOB article explores the concept of value in building design and construction.
BREEAM and Measurabl announce integration to improve the financial performance of commercial real estate.
Rogers Stirk Harbour + Partners' release new images of soon-to-open 3WTC tower in New York.
A document can be called a bond or a guarantee. Does the name matter and what is the difference between them?
New briefing note is launched focusing on increasing knowledge of housing that promotes health and wellbeing.
Arbitration is a private, contractual form of dispute resolution used in the construction industry.
The European Parliament has approved a revised Energy Performance of Buildings directive.
One in six MPs supports the ring-fencing of retentions as proposed in the 'Aldous Bill'.
A stakeholder is anyone who has an interest in the process or outcome of a construction project.