Request for information RFI
A Request for Information (RFI) (occasionally referred to as a Technical Query) is a formal question asked by one party to a contract on a construction project to the other party. Typically this will be a request from the contractor to the client’s consultant team, but it may be between any of the parties, for example from a sub-contractor to a contractor.
Requests for Information are generally required to clarify information in the contract documentation or to provide information that was not complete at the time the contract was agreed.
RFI’s should set out:
- The details of project.
- The details of the party requesting the information.
- The date the query was raised.
- The nature of the information being requested.
- The date by which a response is required.
- Any supporting explanatory documents provided.
It may be necessary for the party receiving the RFI to seek further information from parties with whom they themselves have a contractual relationship in order provide a response. It is good practice to include this information from other parties with the response to the original RFI. This can create a chain of information, where for example a subcontractor requests information from the main contractor, who in turn requests information from the client’s consultant team and so on. It may then be appropriate for responses and any explanatory documents attached to them to be disseminated amongst the wider project team.
This creates a matrix of RFI’s that need to be carefully tracked, responded to and distributed appropriately. This process be managed using an information request schedule, or can be managed electronically.
It is important to record the dates that RFI’s are despatched, the dates by which responses are required and the dates that responses are received to provide evidence in the event that a dispute arises.
Contractually, the requirement to respond to an RFI is created by the obligation to provide further information as is necessary to enable the other party to complete the contract on time. Requests should however give sufficient notice for the respondent to be able to resource and prepare a reply by the date that the information is required. The parties are then entitled to rely on the information provided as correct.
Failure to provide necessary information may qualify as a relevant event for which the contractor may be entitled to an extension of time and to claim loss and expense incurred as a result of any delay. Similarly, a response which constitutes a variation in the nature of the works may qualify as a relevant event for which the contractor may be entitled to an extension of time and to claim loss and expense.
A contractor’s master programme (generally prepared immediately after the execution of the contract and issued to the contract administrator for comment) may constitute a request for information. Similarly, a client information release schedule may constitute a commitment to provide information by certain dates, whether or not these dates are necessary to achieve the completion date.
 Related articles on Designing Buildings Wiki
Featured articles and news
The origins, evolution and future of Level 3 BIM.
For new and returning Urban Design students, check out our article list divided up into the modules you'll be studying.
Report states that health of urban dwellers could be significantly improved by rethinking transport design.
The Kremlin, the centre of Russian power, includes some of the country's finest architecture.
Report launched outlining steps for a national infrastructure system that is efficient, sustainable, and delivers until 2050.
A review of Justin Bere's concise and well-presented introductory guide to Passive House.
This article describes in detail the tender process for a typical commercial construction contract.
What is energy storage, what are the different types and what is its future?
MAD Architects reveal their designs for a state-of-the-art concert hall in Beijing.
Take a look at BIG's designs for two twisting towers in New York City.
'The filing cabinet' which was labelled one of the best British buildings of the 21st century.